Finally Completed definition

Finally Completed. Finally Complete" and "Finally Completion" has the meaning set forth in Section 6.2.
Sample 1Sample 2
Finally Completed means the date when construction is certified by the Architect to be finally completed in accordance with the Contract Documents, as modified by any Change Orders processed under the terms of GC-23.00 below and when the Owner has fully accepted the Project for the use for which it was intended. Such date will be set forth on a letter of acceptance issued by the Owner.
Sample 1Sample 2
Finally Completed or “Final Completion” means the point at which (a) all work on the Project has been completed (including all Punch List Items) pursuant to the Plans and Specifications, the Construction Contract and this Agreement, free of material defects in construction or materials, sufficient to commence occupancy of the Project for its Permitted Uses, all as reasonably determined by Lender and the Construction Consultant, and (b) Borrower has satisfied the conditions of Section 3.7 hereof.
Sample 1Sample 2

Examples of Finally Completed in a sentence

  • Accordingly, CONTRACTOR and the CITY agree that as liquidated damages for delay (but not as a penalty), CONTRACTOR shall pay the CITY two hundred dollars for each day that transpires with the Work not Substantially Completed after the time limit for achieving Substantial Completion specified in section 2.01, and one hundred dollars ($100) for each calendar day that transpires with the Work not Finally Completed after the time limit for achieving Final Completion, as specified in section 2.01.

  • If such inspection, or any subsequent re-inspection required pursuant hereto, discloses any item, whether or not included on the Final Completion Punch List, which must be completed or corrected before Final Completion, Contractor shall, as a condition of Final Completion, complete or correct such item, which shall then be re-inspected to confirm that such Work is Finally Completed.

  • The balance of the fee shall be paid when Construction of the Project is Finally Completed and occupancy of the Project accepted by the County as provided in this Agreement.

  • The first monthly payment shall become due thirty (30) days following the issuance of the Construction Phase Notice to Proceed by the County and the final monthly payment shall be paid only when Construction of the Project is Finally Completed and occupancy of i t is accepted by the County.

  • The final monthly payment shall be paid only when Construction of the Project is Finally Completed and occupancy of it is accepted by the County.

  • The numbers of days (Contract Time) within which the Work is to be Substantially Completed and Finally Completed and ready for acceptance and final payment are set forth in the Bid Form and the Agreement.

  • All work and closeout requirements shall be Finally Completed (“Final Completion Date”) within Thirty (30) consecutive calendar days, including holidays and average rain days, after the date of Substantial Completion.

  • In addition, the Contractor shall pay the sum of one hundred dollars ($100.00) for each calendar day that transpires with the Project not Finally Completed after the time limit for achieving Final Completion specified in the above paragraph.

  • If the Improvements are not Substantially Complete on or before the Substantial Completion Date or Finally Completed on or before the Final Completion Date for any reason whatsoever, then the same shall constitute an Event of Default hereunder.

  • Coates advised the original Reproduc- tive Health and HIV Research Unit National Youth Survey team.


More Definitions of Finally Completed

Finally Completed means that all of the requirements for the Coronado South Improvements to be Substantially Completed shall have been satisfied, except that Buyer and Seller shall have agreed (or the Independent Consultant shall have determined) in accordance with this Section 5.8(b)(iv) that one hundred percent (100%) of the Coronado South Improvements shall have been completed; and (D) the "Coronado South Improvements Contracts" means those documents listed on Schedule 5.8(b) attached hereto.
Sample 1Sample 2
Finally Completed means: (a) in respect of Open Space when (following Practical Completion and inspection) all maintenance and remedial works required by the Council have been certified as complete by the Council; (b) in respect of SANG and/or Additional SANG, when the SANG and/or Additional SANG and any necessary ancillary facilities such as but not limited to a car park (where applicable) are certified as complete by the Council and the SANG and/or Additional SANG is available for public use; (c) in respect of Works In Kind to deliver the Health Facility, when the Health Facility is fitted out and available for beneficial Occupation; (d) in respect of the Works In Kind to deliver the Eastern Junction, when the Eastern Junction is adopted as highway maintainable at the public expense (e) in respect of the Community Hubs when the Community Hub is fully fitted out and available for beneficial Occupation and "Final Completion" shall be construed accordingly
Sample 1
Finally Completed shall have a corresponding meaning;
Sample 1
Finally Completed means the date all Construction of the GF Plant or any component part of the City Infrastructure, as the case may be, has been fully completed and finally accepted by the City, as determined by the City Engineer, City Planner, City Inspector, City Fire Code Official, City Water Works Director and City Administrator. The City Administrator shall provide written notice to the Developer upon determining that the GF Plant or any components of the City Infrastructure are Finally Completed. Provided, however that such officials will not unreasonably withhold approvals or written acknowledgement that the GF Plant or any component part of the City Infrastructure, as the case may be, is Finally Completed.
Sample 1
Finally Completed means the date the Public Improvements have been finally and fully completed to the satisfaction of the City, as determined by the City Engineer, City Planner, and City Inspector in the exercise of their discretion. The City Engineer, City Planner, and City Inspector shall provide written notice to the Developer upon determining the Public Improvements are Finally Completed.
Sample 1
Finally Completed means: (a) the occurrence of Substantial Completion; (b) the completion of all Punch List Items; and (c) the delivery of all items required by Section 7.11(d).
Sample 1

Related to Finally Completed

  • Substantially Completed or “Substantial Completion” means that (i) Landlord has completed the Finish Work in accordance with the Working Plans, except for (x) minor details of construction that will not unreasonably interfere with Tenant’s use of the Premises (collectively, “Punch List Items”), which Punch List Items shall be completed by Landlord as soon as reasonably possible, and (y) any part of the Finish Work that is not completed due to a Tenant Delay; and (ii) Landlord has obtained a valid temporary or permanent certificate of occupancy for the Premises or, alternatively, Landlord has completed all the Finish Work necessary to entitle Landlord to the issuance of a temporary or permanent certificate of occupancy other than any Finish Work that is not completed due to a Tenant Delay. A “Tenant Delay” will be deemed to have occurred if the completion of the Finish Work is delayed due to any act or omission by Tenant or Tenant’s Visitors, including, but not limited to, delays due to changes in or additions to the Finish Work requested by Tenant, delays in submission of information or estimates, delays in giving authorizations or approvals, delays due to the postponement of any work at the request of Tenant, or delays caused by Tenant’s performance of (or its contractors’ performance of) the Tenant’s Work, but specifically excluding any delay arising from an action or inaction of Landlord, Landlord’s employees, Landlord’s agents or any combination thereof. Notwithstanding the foregoing, no Tenant Delay shall be deemed to have occurred unless Landlord notifies Tenant of such delay, and Tenant fails to cure such circumstances giving rise to such Tenant Delay within two (2) business days following the date Tenant obtains actual knowledge thereof.

  • Substantially Complete “Substantially Completed” or “Substantial Completion” with regard to the Shell and Core Improvements shall mean the later to occur of (i) the substantial completion of construction of the Shell and Core Improvements, as certified by the Project Architect, pursuant to and evidenced by a fully executed AIA G704 form signed by Landlord, Non-TI Construction Manager and the Project Architect, with the exception of any Punch List Items (as defined below), and (ii) the issuance by the City of Cambridge of a certificate of occupancy for the Shell and Core (unless such certificate is not available due to requirements of the Tenant Improvements or improvements to other tenant spaces that in either case preclude issuance of a certificate of occupancy, in which case a certificate of occupancy shall not be a condition precedent to Substantial Completion, but Landlord shall obtain such a certificate within a reasonable time after such requirements have been satisfied). Punch List Items shall be diligently completed by Landlord within a reasonable time, provided that Punch List Items which arise due to a delayed delivery of such Punch List Item or material portion thereof shall be completed no later than ninety (90) days after Substantial Completion (except for items which cannot be completed until the Tenant Improvements are completed by Tenant, or for items affected by seasonal conditions, each of which shall be completed as soon as practicable). The term “Punch List Items” shall mean minor items of completion, correction or repair with respect to the Non-TI Project Improvements, which, by their nature, will not interfere with, or impair in any material respect, Tenant’s use or occupancy of the Project for the purposes contemplated under the Lease, and which will not delay Tenant’s commencement of business operations in the Premises. Following the Substantial Completion of the Shell and Core Improvements, Landlord shall use commercially reasonable efforts to complete any remaining Site Improvements that are not complete as of the date of Substantial Completion of the Shell and Core Improvements as soon as reasonably practicable, which for all seasonal components of the Site Improvements shall be prior to the end of the first full planting season that begins after the date of Substantial Completion of the Shell and Core Improvements.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Final Completion Date means the date on which Final Completion occurs.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Ready for Occupancy means a mobile or manufactured home

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Tenant Improvements Defined in Exhibit B, if any.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Practical Completion means the completion of the Project where the building is fit for occupancy and/or purpose.

  • Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08 A.

  • Completion Deadline means the date by which the transactions contemplated by this Agreement are to be completed, which date shall be December 31, 2006;

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Final completion and acceptance means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

  • Construction Work means any work in connection with⎯

  • Notice of Completion means a document issued by the Department or Delegated Agency at the end of project construction when all items and conditions of the approved Sediment and Stormwater Management Plan have been satisfied, post construction verification documents demonstrate that the stormwater management systems have been constructed in accordance with the approved Sediment and Stormwater Management Plan, and final stabilization of disturbed areas on the site has been achieved.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

OSZAR »